Browsing Tag

homebuyer rights

87 posts
A Mumbai housewife received a shocking ₹55 lakh tax demand on a flat she never paid for. Her only fault? Her name was on the agreement. What happened next will relieve many Indian families...

No Date, No Justice: MahaRERA Rejects Homebuyer’s Delay Claim Over Vague 2011 AFS

In a controversial order, MahaRERA has rejected a homebuyer’s claim for interest on delayed possession solely because his 2011 Agreement for Sale did not mention any specific date. The Authority dismissed the complaint filed by Imran Haedr against K.K. Constructions but directed a refund as per contract terms. The ruling highlights the risks of signing agreements with vague possession clauses even in the RERA era.
“Getting approvals, sanctions, environmental clearance, etc., is the builder’s responsibility. Buyers cannot be made to suffer for these delays,” ruled MahaRERA while directing full refund with interest to homebuyers in the Vardhaman Park project.

Approvals & Clearances Builder’s Duty, Home Buyers Can’t Suffer Delays

“Getting approvals, sanctions, environmental clearance, etc., is the builder’s responsibility. Buyers cannot be made to suffer for these delays,” ruled MahaRERA while directing full refund with interest to homebuyers in the Vardhaman Park project.
A Mira Road builder collected over ₹28 lakh from a homebuyer across four years, never once executed an Agreement for Sale, then cancelled his flat for "non-payment." The Maharashtra Real Estate Appellate Tribunal wasn't buying it — and delivered one of the most comprehensive homebuyer-friendly rulings in recent memory.

Builder Pockets 90% of Your Money,Then Cancels Your Flat — Tribunal Says: Not on Our Watch

A Mira Road builder collected over ₹28 lakh from a homebuyer across four years, never once executed an Agreement for Sale, then cancelled his flat for “non-payment.” The Maharashtra Real Estate Appellate Tribunal wasn’t buying it — and delivered one of the most comprehensive homebuyer-friendly rulings in recent memory.
MahaRERA has dismissed a high-value complaint by steel supplier Nikant Steel against Sheth Developers, ruling that the dispute over three flats in the delayed Sheth Blue Ivy project does not qualify as a standard RERA promoter-allottee matter due to documentation discrepancies and its origin in a commercial debt.

MahaRERA Orders Interest for Delayed Possession in Kalyan’s Vrundavan Project

MahaRERA directs Shree Vasturachana Developers to pay interest for delayed possession in Vrundavan project, Kalyan, as physical handover without OC ruled invalid. Buyer wins compensation under Section 18.
The Rais booked a flat in 2013, paid ₹79 lakh, and were promised possession by December 2017. What followed was a developer collapse, a project takeover, a majority consent exercise they never agreed to — and a regulator that told them to cooperate. The tribunal disagreed.

MahaRERA Told Homebuyers to Cooperate. Tribunal Tells Builder to Pay Up

The Rais booked a flat in 2013, paid ₹79 lakh, and were promised possession by December 2017. What followed was a developer collapse, a project takeover, a majority consent exercise they never agreed to — and a regulator that told them to cooperate. The tribunal disagreed.